Terms & Conditions

1. Acceptance of Terms

By accessing and using the Angels Green Hardscapes website and services, you accept and agree to be bound by the terms and provision of this agreement. If you do not agree to abide by the above, please do not use this service.

2. Service Description

Angels Green Hardscapes provides hardscaping, landscaping, and concrete services in the Tri-State Area (New Jersey, Pennsylvania, Delaware). Our services include but are not limited to:

• Custom patio design and installation
• Landscape design and implementation
• Concrete work and decorative finishes
• Retaining walls and walkways
• Outdoor living space construction

3. Estimates and Quotes

3.1 Initial Estimates

All initial estimates are based on available information and may be subject to change upon detailed site inspection. Final pricing will be provided after thorough evaluation of the project site.

3.2 Quote Validity

Quotes are valid for 30 days from the date of issue. Material prices and labor costs may change after this period, requiring quote updates.

4. Project Terms

4.1 Site Preparation

Property owners are responsible for:

• Clearing the work area of personal items and obstacles
• Providing access to water and electricity if required
• Securing pets and children during work hours
• Obtaining necessary permits and approvals

4.2 Weather and Delays

Project timelines may be affected by:

• Weather conditions and seasonal factors
• Material availability and delivery delays
• Site conditions discovered during construction
• Client-requested changes or additions

5. Payment Terms

5.1 Payment Schedule

Payment terms will be outlined in your project contract. Typically, we require:

• 50% deposit upon contract signing
• Remaining balance upon project completion
• Additional payments for change orders or additions

5.2 Late Payments

Late payments may result in project delays or suspension of work. Interest may be charged on overdue accounts.

6. Warranties and Guarantees

6.1 Workmanship Warranty

We provide a 2-year warranty on workmanship for all projects. This covers defects in installation and construction methods.

6.2 Material Warranties

Material warranties are provided by manufacturers and vary by product. We will provide warranty information for all materials used in your project.

6.3 Warranty Limitations

Warranties do not cover:

• Damage caused by improper maintenance
• Natural wear and tear over time
• Damage from extreme weather events
• Modifications made by others

7. Liability and Insurance

7.1 Our Insurance

Angels Green Hardscapes maintains comprehensive liability insurance and workers' compensation coverage for all projects.

7.2 Limitation of Liability

Our liability is limited to the amount paid for the specific project. We are not responsible for:

• Consequential damages
• Loss of use or enjoyment
• Indirect damages
• Punitive damages

8. Dispute Resolution

In the event of a dispute, we encourage direct communication to resolve issues. If resolution cannot be reached, disputes will be handled through mediation or legal proceedings in the state of New Jersey.

9. Website Terms

9.1 Content Accuracy

While we strive for accuracy, website content may not reflect current availability, pricing, or service offerings. Please contact us for current information.

9.2 Intellectual Property

All content on this website, including images, text, and design, is the property of Angels Green Hardscapes and is protected by copyright laws.

10. Privacy and Data

Your privacy is important to us. Please review our Privacy Policy for information about how we collect, use, and protect your personal information.

11. Changes to Terms

We reserve the right to modify these terms at any time. Changes will be effective immediately upon posting on our website. Continued use of our services constitutes acceptance of modified terms.

12. Contact Information

If you have questions about these terms and conditions, please contact us:

13. Governing Law

These terms and conditions are governed by the laws of the State of New Jersey. Any legal proceedings will be conducted in the courts of New Jersey.

14. Severability

If any provision of these terms is found to be unenforceable, the remaining provisions will continue in full force and effect.